banner ad
Experts Logo
Articles Pen

FEATURED ARTICLES BY LONG INTERNATIONAL

Featured articles by Long International are shown together on this page and the following pages, if any.
Search articles by title, description, author etc.
Sort Featured Articles
richard_long_photo.jpg

11/25/2020· Construction

Construction Contract Notice Letters

By: Long International

Most construction contracts require written notice for changes, differing site conditions, extra work, or other events which may affect the contractor’s time and cost of performance. The process of giving “notice” is vital to triggering the contract mechanisms that allow the contractor to pursue additional time and cost and to reserve its rights to recover for any unforeseen...

douglas-bassett-construction-project-management-expert-photo.jpg

10/21/2020· Construction

COVID-19 Claim Management on Construction Projects

By: Long International

The COVID-19 pandemic has changed the internal and external project execution environments. The pandemic has caused impacts of varying degrees to nearly every aspect of projects involving the activity of people. Ordinary practices in the creation of project documentation are robust and are utilized to support the analysis of construction claims. Although project productivity losses may be demonstrable, providing compelling evidence and proof that the losses were caused by the pandemic may not be as easy to demonstrate.

long-international-logo.jpg

12/28/2019· Construction

As-Built But-For Schedule Delay Analysis

By: Long International

An As-Built But-For Schedule Delay Analysis (ABBF) is a retrospective CPM schedule delay analysis technique that determines the earliest date that the required mechanical completion activity, project completion activity, or various milestone activities could have been achieved but-for the owner-caused compensable delays that occurred during the project.

long-international-logo.jpg

3/12/2018· Construction

Proving the Cause-Effect Linkage

By: Long International

Contractor’s claim submittals and expert reports are often deficient in proving causation, i.e., the cause-effect linkage. These claims generally outline the owner-caused impacts and separately calculate quantum; however, the two are often not linked in any meaningful way. Most claims are settled prior to a decision by a panel, court, or board, and therefore these deficiencies are not made apparent. Yet, a well-prepared claim document which includes a persuasive and accurate causeeffect analysis can greatly improve the contractor’s chances of a successful recovery, either through negotiations or in arbitration/litigation. This analysis is difficult and often costly to prepare, and is therefore not performed in many disputes, which may be the reason why the claims fail.

long-international-logo.jpg

11/13/2017· Construction

Acceleration Claims on Engineering and Construction Projects

By: Long International

Time is money especially on engineering and construction projects. Because delays in the completion of the project usually result in increased owner, engineer, and contractor costs, the overall time of performance is vital to the financial success of the project. The importance of time is evidenced by the significant role played by CPM schedules, completion dates, and milestones in the bidding and awarding of engineering and construction contracts. The desire to minimize costs and the time of performance often causes the occurrence of acceleration.

long-international-logo.jpg

10/4/2017· Construction

A Reasonable Method to Estimate Loss of Labor Productivity Due to Overtime

By: Long International

In the construction industry, it is largely agreed that overtime work adversely affects labor productivity. However, there is no universally accepted method for estimating the resulting loss of productivity, and many of the studies commonly used to estimate such losses have been subject to criticism by industry experts and the courts.

long-international-logo.jpg

8/2/2017· Construction

The Collapsed As-Built Windows Schedule Analysis Method

By: Long International

The Collapsed As-Built Windows Schedule Analysis (AACE® International Recommended Practice 29R-03, Method Implementation Protocol 3.9) is a modeled, subtractive, multiple-base method. It is a retrospective CPM schedule analysis which is typically used to prove entitlement for compensable delay and assess concurrency of delay within a window of time. The analysis simulates the as-built conditions within a schedule window and then delays are removed from the CPM model. If the forecasted project finish date “collapses” but-for or absent compensable delays, then entitlement for compensable time-related costs can be demonstrated. This article addresses the usage of the Collapsed As-Built Windows protocol and the advantages and disadvantages of the methodology.

long-international-logo.jpg

9/27/2013· Construction

Discrete Damages/Cost Variance Analysis Method for Quantifying Damages in Construction Claims

By: Long International

The "discrete damages/cost variance analysis method" for quantifying construction claim damages involves the specific distribution of all costs incurred on the project rather than quantifying only certain parts of the cost or damage analysis as may be used in the other methods.

long-international-logo.jpg

9/4/2013· Construction

Developing Subcontract Pricing As Applied to Building Construction

By: Long International

ABSTRACT - This paper provides guidelines to commercial construction cost engineers for the development of a plan for obtaining and utilizing subcontractor cost information for use in bidding, procurement, scheduling, change order management, and claim management. The paper is based upon personal field experience gained in cost engineering, scheduling, bidding, planning, contracting, and claim analyses.

long-international-logo.jpg

8/13/2013· Construction

Construction Claims For Variation in Quantity

By: Long International

A component of a construction claim often relates to the cost, quantity, and quality of the materials that the contractor installed on a project. The contractor frequently purchases these materials and agrees to install the quantities of materials on a unit price basis, i.e., a unit price that includes both the cost of the materials and the cost to install them.

Featured resources

Experts.com-No broker Movie Ad

Follow us

linkedin logo youtube logo rss feed logo
;