banner ad
Experts Logo

articles

Proving the Cause-Effect Linkage

By: Richard J. Long, P.E., P.Eng., Rod C. Carter, CCP, PSP and Harold E. Buddemeyer, Jr.
Tel: (303) 972-2443
Email: Long International, Inc.


View Profile on Experts.com.


1. INTRODUCTION

Contractor's claim submittals and expert reports are often deficient in proving causation, i.e., the cause-effect linkage. These claims generally outline the owner-caused impacts and separately calculate quantum; however, the two are often not linked in any meaningful way. Most claims are settled prior to a decision by a panel, court, or board, and therefore these deficiencies are not made apparent. Yet, a well-prepared claim document which includes a persuasive and accurate causeeffect analysis can greatly improve the contractor's chances of a successful recovery, either through negotiations or in arbitration/litigation. This analysis is difficult and often costly to prepare, and is therefore not performed in many disputes, which may be the reason why the claims fail.

For the analyst seeking to show the cause-effect linkage in a cumulative impact of changes claim, the task is even more difficult. By an earlier definition, cumulative impact is "exclusive of that local disruption that can be ascribed to a specific change," 1 or stated another way, cumulative impact cannot be ascribed to a specific change. Yet court and board decisions have shown that simply demonstrating that numerous changes existed, and that the contractor suffered a loss of productivity, is often not sufficient for recovery. This dichotomy is difficult to overcome.

In Luria Bros. & Co. v. United States, the court stated: "It is a rare case where loss of productivity can be proven by books and records; almost always it has to be proven by the opinion of expert witnesses." 2 Proving causation in direct disruption or cumulative disruption claims most often requires a qualified expert, as well as detailed and complete contemporaneous project documentation. The following suggestions, while case sensitive and highly dependent on the detail in the project record, provide several ideas on linking excessive changes with a loss of productivity:

  • Prepare a schedule analysis (see Section 2);
  • Track the impact on an activity or crew (see Section 3);
  • Show how the site environment changed from plan (see Section 4);
  • Tell the factual story with graphics (see Section 5); and
  • Prepare a cause-effect matrix (see Section 6).

This article is a slightly modified chapter from the book, Cumulative Impact and Other Disruption Claims in Construction, published in 2014.

2. SCHEDULE ANALYSES

Contractors often utilize a schedule analysis to identify and help quantify the effects of ownercaused changes and impacts that delayed their work. As a result of project delay, the contractor may accelerate, increase its manpower, work excessive overtime, experience trade stacking and crowded conditions, and allege compensable loss of labor productivity. However, without support from a schedule analysis, the contractor makes a quantum leap from proving the owner-caused delays and impacts, to alleging that 100 percent of the productivity loss is compensable due solely to the owner-caused delays and impacts.

The contractor's own problems may have contributed to the productivity loss and must be considered. A more appropriate analysis of the increased labor costs would be to allocate the labor cost increases to both the owner and the contractor according to their respective share of delays, disruptions, and problems.

Contractors are not legally bound to demonstrate delayed performance or project delay to recover for loss of productivity.3 However, the relationship between delay and productivity is evident. If a contractor is delayed, it may have to recover that delay through acceleration measures, at the expense of productivity. Likewise, if a contractor suffers poor productivity, it may lead to schedule delay.

When courts and boards are considering causation in respect of disruption claims, the proof of delay, or lack thereof, is at least one consideration. In Charles G. Williams Construction, the board found that the contractor had proven it was delayed unreasonably by the government's actions, and therefore the contractor was entitled to damages for both extended overhead and disruption.4 In discussing proof of causation in J. A. Jones, the board emphasized that the contractor had not proven it was delayed as a result of compensable issues, which was one basis for its denying the contractor's cumulative impact claim.5 In Advanced Engineering & Planning Corp., the board, in denying the contractor's disruption claim for lack of causation, cited the contractor's failure to use a resource-loaded CPM schedule as required by contract:

"In this connection, we have found, had it submitted and updated a "resource loaded" CPM as required by Standard Item No. 009-60, AEPCO could have tracked disruptive impact through the schedule..." 6

Based upon the above, it is evident that a schedule analysis can be helpful in demonstrating causation. Even if a formal schedule analysis is not prepared, bar charts, histograms, and other data sourced from the project schedule can be useful in demonstrating causation. Several examples of this are provided in this chapter.

3. TRACKING IMPACTS BY ACTIVITY OR CREW

. . .Continue to read rest of article (PDF).


Long International provides expert claims analysis, dispute resolution, and project management services to the Process Plant Engineering and Construction industry worldwide. Our primary focus is on petroleum refining, petrochemical, chemical, oil and gas production, mining/mineral processing, power, cogeneration, and other process plant and industrial projects. We also have extensive experience in hospital, commercial and industrial building, pipeline, wastewater, highway and transit, heavy civil, microchip manufacturing, and airport projects.

©Copyright - All Rights Reserved

DO NOT REPRODUCE WITHOUT WRITTEN PERMISSION BY AUTHOR.

Related articles

Jeffrey-Weinstein-Architect-Construction-Management-Expert-Photo.jpg

9/11/2017· Construction

Common Sense Strategies for Avoiding Construction Litigation

By: Jeffrey P. Weinstein

ln our current climate of economic prosperity and rising real estate values, the prevalence and usefulness of construction litigation may be on the wane. Much of the litigation and expert opinion in recent years has resulted in unrealistic repair schemes for the sole purpose of producing a settlement among parties to the litigation. When a plaintiff expert recommends a "remove and replace in its entirety"1 scenario (for example, arguing that all exterior stucco must be demolished and reinstalled due to a lack of expansion joints), the defense expert frequently advocates a more modest "fix what's broken" scheme to provide a minimum repair at the lowest cost. This process consumes considerable time and resources, and creates a difficult environment in which to craft a settlement. More often than not, neither party is pleased with the outcome; unreasonable plaintiff positions often result in settlement amounts ranging between 15 to 25 percent of the claim amount.

michael-panish-logo.gif

12/11/2015· Construction

Modular Cabinet Systems Retail Store Fixtures: Injuries from Improper Installation

By: Michael Panish

I have been the retained expert witness by both the plaintiff and defendant to determine the causes of a variety of significant injuries that have happened as a result of improper cabinet and millwork installation practices. In most claims, if product abuse or deferred condition was not the reason for the injury, poor installation practices that have omitted required hardware was to blame. Architectural millwork injuries have occurred repeatedly in shopping centers and malls, hotels, hospitals, airports, and offices throughout the country. Casinos and restaurants are also routinely the location of significant cabinetry related failures leading to serious injuries. Many offices and industrial buildings that utilize modular furniture have had employees injured by improper or completely unattached components. In my other articles, improperly attached architectural millwork has been discussed. Heavy mirrors and headwalls have fallen upon hotel guests while they were asleep in bed. Generally, these failures occur due to lack of appropriate fasteners, missed structural connections, or product tampering.

long-international-logo.jpg

1/8/2025· Construction

The Art of Construction Contract Correspondence

By: Long International

Correspondence on any construction project, irrespective of its size and value, is a crucial element of the contract administration process. To be effective, correspondence requires measured, complete, and structured management. However, project managers, contract managers, and administrators often fail to implement or even recognize simple basic guidelines

;
Experts.com-No broker Movie Ad

Follow us

linkedin logo youtube logo rss feed logo
;