banner ad
Experts Logo

articles

The Collapsed As-Built Windows Schedule Analysis Method

By: Long International, Inc. - Andrew Avalon, P.E., PSP and Ronald J. Rider, MBA
Tel: (303) 972-2443
Email:Mr. Avalon


View Profile on Experts.com.


ABSTRACT

The Collapsed As-Built Windows Schedule Analysis (AACE® International Recommended Practice 29R-03, Method Implementation Protocol 3.9) is a modeled, subtractive, multiple-base method. It is a retrospective CPM schedule analysis which is typically used to prove entitlement for compensable delay and assess concurrency of delay within a window of time. The analysis simulates the as-built conditions within a schedule window and then delays are removed from the CPM model. If the forecasted project finish date "collapses" but-for or absent compensable delays, then entitlement for compensable time-related costs can be demonstrated. This article addresses the usage of the Collapsed As-Built Windows protocol and the advantages and disadvantages of the methodology.

1. INTRODUCTION

It is common that an unanticipated event or issue may cause delay and extend the overall completion of a project. It is also common that project stakeholders may dispute the responsibility for a project issue that caused delay and extended the overall completion of a project. A project issue can become contested, cause multiple delays, affect several areas of a project, occur at different points in time, and become intertwined with non-contested issues. To achieve an equitable resolution of a contested project issue that caused delay, it is imperative for an analyst to answer the following basic questions:

  • Who caused the delay?
  • Why did the delay occur?
  • What impact did the delay cause?
  • Where did the delay occur?
  • When did the delay occur?

On large and complex projects, the process of evaluating delay issues is further complicated when the schedule file is comprised of numerous process areas/units, thousands of activities with activity groups spanning many months or years, and multiple critical and near-critical paths. One retrospective forensic schedule analysis that can be used to evaluate concurrency and quantify compensable delay is the Collapsed As-Built schedule analysis method applied on a windows basis (AACE® International Recommended Practice 29R-03, MIP 3.9).

2. THE COLLAPSED AS-BUILT WINDOWS ANALYSIS DEFINED


. . .Continue to read rest of article (PDF).


Long International provides expert claims analysis, dispute resolution, and project management services to the Process Plant Engineering and Construction industry worldwide. Our primary focus is on petroleum refining, petrochemical, chemical, oil and gas production, mining/mineral processing, power, cogeneration, and other process plant and industrial projects. We also have extensive experience in hospital, commercial and industrial building, pipeline, wastewater, highway and transit, heavy civil, microchip manufacturing, and airport projects.

©Copyright - All Rights Reserved

DO NOT REPRODUCE WITHOUT WRITTEN PERMISSION BY AUTHOR.

Related articles

long-international-logo.jpg

3/12/2018· Construction

Proving the Cause-Effect Linkage

By: Long International

Contractor’s claim submittals and expert reports are often deficient in proving causation, i.e., the cause-effect linkage. These claims generally outline the owner-caused impacts and separately calculate quantum; however, the two are often not linked in any meaningful way. Most claims are settled prior to a decision by a panel, court, or board, and therefore these deficiencies are not made apparent. Yet, a well-prepared claim document which includes a persuasive and accurate causeeffect analysis can greatly improve the contractor’s chances of a successful recovery, either through negotiations or in arbitration/litigation. This analysis is difficult and often costly to prepare, and is therefore not performed in many disputes, which may be the reason why the claims fail.

michael-panish-logo.gif

12/11/2015· Construction

Modular Cabinet Systems Retail Store Fixtures: Injuries from Improper Installation

By: Michael Panish

I have been the retained expert witness by both the plaintiff and defendant to determine the causes of a variety of significant injuries that have happened as a result of improper cabinet and millwork installation practices. In most claims, if product abuse or deferred condition was not the reason for the injury, poor installation practices that have omitted required hardware was to blame. Architectural millwork injuries have occurred repeatedly in shopping centers and malls, hotels, hospitals, airports, and offices throughout the country. Casinos and restaurants are also routinely the location of significant cabinetry related failures leading to serious injuries. Many offices and industrial buildings that utilize modular furniture have had employees injured by improper or completely unattached components. In my other articles, improperly attached architectural millwork has been discussed. Heavy mirrors and headwalls have fallen upon hotel guests while they were asleep in bed. Generally, these failures occur due to lack of appropriate fasteners, missed structural connections, or product tampering.

Jeffrey-Weinstein-Architect-Construction-Management-Expert-Photo.jpg

9/11/2017· Construction

Common Sense Strategies for Avoiding Construction Litigation

By: Jeffrey P. Weinstein

ln our current climate of economic prosperity and rising real estate values, the prevalence and usefulness of construction litigation may be on the wane. Much of the litigation and expert opinion in recent years has resulted in unrealistic repair schemes for the sole purpose of producing a settlement among parties to the litigation. When a plaintiff expert recommends a "remove and replace in its entirety"1 scenario (for example, arguing that all exterior stucco must be demolished and reinstalled due to a lack of expansion joints), the defense expert frequently advocates a more modest "fix what's broken" scheme to provide a minimum repair at the lowest cost. This process consumes considerable time and resources, and creates a difficult environment in which to craft a settlement. More often than not, neither party is pleased with the outcome; unreasonable plaintiff positions often result in settlement amounts ranging between 15 to 25 percent of the claim amount.

;
Experts.com-No broker Movie Ad

Follow us

linkedin logo youtube logo rss feed logo
;