Florida Office:
Andrew Avalon, PE, PSP
President
8633 Willow Kane Court
Orlando, FL 32835
T: (407) 445-0825 F: (407) 445-0821
Long International provides expert claims analysis, dispute resolution, and project management services to the Process Plant Engineering and Construction industry worldwide. Our primary focus is on petroleum refining, petrochemical, chemical, oil and gas production, mining/mineral processing, power, cogeneration, and other process plant and industrial projects. We also have extensive experience in hospital, commercial and industrial building, pipeline, wastewater, highway and transit, heavy civil, microchip manufacturing, and airport projects.
| Richard J. Long, PE, Founder and Chief Executive Officer of Long International has over 40 years of U.S. and international consulting experience involving construction contract disputes analysis and resolution, arbitration/litigation support and expert testimony, project management, engineering/construction management, cost and schedule control, and process engineering. He has presented and published numerous articles on the subjects of claims analysis, entitlement issues, CPM schedule and damages analyses, cumulative impact claims, and claims prevention. As an internationally recognized expert in the analysis and resolution of complex construction disputes for 30 years, Mr. Long has served as the lead expert on over 300 projects having claims ranging in size from US$100,000 to over US$2 billion.
|
| Andrew Avalon, PE, PSP is President of Long International and has over 30 years of engineering, construction management and claims consulting experience. He is an expert in the preparation and evaluation of construction claims, insurance claims, schedule delay analysis, arbitration/ litigation support, and dispute resolution. Mr. Avalon has prepared more than 30 CPM schedule analyses, expert witness reports, and testified in deposition, mediation, and arbitration proceedings. In addition, he has published numerous articles on the subjects of CPM schedule delay analysis and entitlement issues affecting construction claims and is a contributor to AACE® International’s Recommended Practice No. 29R-03 for Forensic Schedule Analysis. He has served as a Project Manager on numerous claims ranging in size from US$100,000 to over US$1 billion.
|
| W. Tom Thweatt is a Senior Principal with Long International and has over 40 years of engineering, construction, and management consulting experience. He has extensive experience in major U.S. and international refining, chemical, petrochemical, offshore oil & gas development, pipeline, infrastructure, and thermal / hydroelectric power generation projects ranging from US$40 million to US$12 billion. He has worked extensively in projects that were executed by multi-national joint ventures on both the owner’s and the contractor’s sides. Mr. Thweatt has served on Joint Venture and Consortium Executive Committees and has participated directly in claims negotiations and settlement agreements in excess of US$100 million.
|
Contractor’s claim submittals and expert reports are often deficient in proving causation, i.e., the cause-effect linkage. These claims generally outline the owner-caused impacts and separately calculate quantum; however, the two are often not linked in any meaningful way. Most claims are settled prior to a decision by a panel, court, or board, and therefore these deficiencies are not made apparent. Yet, a well-prepared claim document which includes a persuasive and accurate causeeffect analysis can greatly improve the contractor’s chances of a successful recovery, either through negotiations or in arbitration/litigation. This analysis is difficult and often costly to prepare, and is therefore not performed in many disputes, which may be the reason why the claims fail.
The leader of a corporation or project is the individual who must ultimately be willing to take responsibility for results. Within the context of an organization or team made up of individuals, it is the collective performance of the individuals, as a team, that defines the results of the whole. While it can be said that the best motivation is internal motivation as opposed to external motivation, the leader is ultimately the one responsible for creating the conditions where motivation can thrive.
11/13/2017
· ConstructionTime is money especially on engineering and construction projects. Because delays in the completion of the project usually result in increased owner, engineer, and contractor costs, the overall time of performance is vital to the financial success of the project. The importance of time is evidenced by the significant role played by CPM schedules, completion dates, and milestones in the bidding and awarding of engineering and construction contracts. The desire to minimize costs and the time of performance often causes the occurrence of acceleration.
In the construction industry, it is largely agreed that overtime work adversely affects labor productivity. However, there is no universally accepted method for estimating the resulting loss of productivity, and many of the studies commonly used to estimate such losses have been subject to criticism by industry experts and the courts.
The Collapsed As-Built Windows Schedule Analysis (AACE® International Recommended Practice 29R-03, Method Implementation Protocol 3.9) is a modeled, subtractive, multiple-base method. It is a retrospective CPM schedule analysis which is typically used to prove entitlement for compensable delay and assess concurrency of delay within a window of time. The analysis simulates the as-built conditions within a schedule window and then delays are removed from the CPM model. If the forecasted project finish date “collapses” but-for or absent compensable delays, then entitlement for compensable time-related costs can be demonstrated. This article addresses the usage of the Collapsed As-Built Windows protocol and the advantages and disadvantages of the methodology.
The "discrete damages/cost variance analysis method" for quantifying construction claim damages involves the specific distribution of all costs incurred on the project rather than quantifying only certain parts of the cost or damage analysis as may be used in the other methods.
ABSTRACT - This paper provides guidelines to commercial construction cost engineers for the development of a plan for obtaining and utilizing subcontractor cost information for use in bidding, procurement, scheduling, change order management, and claim management. The paper is based upon personal field experience gained in cost engineering, scheduling, bidding, planning, contracting, and claim analyses.
A component of a construction claim often relates to the cost, quantity, and quality of the materials that the contractor installed on a project. The contractor frequently purchases these materials and agrees to install the quantities of materials on a unit price basis, i.e., a unit price that includes both the cost of the materials and the cost to install them.
12/17/2012
· ConstructionMost construction contracts, whether they are standard or customized forms, usually contain specific provisions related expressly to the process of giving "notice." The notice generally refers to an obligation on the part of the Contractor to notify the relevant party administering the contract, normally the architect, resident engineer, or owner's representative, of a claim or change event that gives rise to possible additional entitlement for time and/or cost.
The equitable allocation of responsibility for project delays is essential to the resolution of many construction disputes. Contractors frequently assert that they have been delayed for reasons beyond their control. Owners often remain unconvinced that the Contractor is legitimately entitled to a time extension or delay, acceleration and loss of productivity damages.
Ole E. Haaland, PE, has thirty four years experience in Power Production, Design, Construction, and Commissioning, with 30+ years managing people and projects. Mr. Haaland's experience is in conventional, nuclear, and alternate fuel power plant mechanical and electrical systems. He has performed as Project Manager, Construction Manager, and Commissioning Manager for several Greenfield power projects.
