Florida Office:
Andrew Avalon, PE, PSP
Chairman
8633 Willow Kane Court
Orlando, FL 32835
aavalon@long-intl.com
T: (407) 445-0825 F: (407) 445-0821
Long International provides expert claims analysis, expert testimony, dispute resolution, and project management services to the process plant engineering and construction industry worldwide. Our primary focus is on petroleum refining, petrochemical, chemical, oil and gas production, mining/mineral processing, power, cogeneration, and other process plant and industrial projects. We also have extensive experience in hospital, commercial and industrial building, pipeline, wastewater, highway and transit, heavy civil, microchip manufacturing, and airport projects.
| Richard J. Long, PE, Founder and Chief Executive Officer of Long International has over 40 years of U.S. and international consulting experience involving construction contract disputes analysis and resolution, arbitration/litigation support and expert testimony, project management, engineering/construction management, cost and schedule control, and process engineering. He has presented and published numerous articles on the subjects of claims analysis, entitlement issues, CPM schedule and damages analyses, cumulative impact claims, and claims prevention. As an internationally recognized expert in the analysis and resolution of complex construction disputes for 30 years, Mr. Long has served as the lead expert on over 300 projects having claims ranging in size from US$100,000 to over US$2 billion.
|
 | Rod C. Carter, CCP, PSP is President of Long International and has over 20 years of experience in construction project controls, contract disputes and resolution, negotiations, mediation, arbitration support, and expert testimony related to scheduling, loss of productivity, and quantum issues. He has experience in entitlement, schedule, and damages analyses on over 30 construction disputes ranging in value from US$100,000 to US$7 billion concerning oil and gas, oil refinery, LNG, heavy civil, nuclear, environmental, chemical, power, industrial, commercial, and residential construction projects. Mr. Carter is proficient in the use of Primavera P6 and P3 software, and he has extensive experience in assessing the impact to engineering and construction works of RFIs, change orders and other events. Mr. Carter specializes in loss of productivity, cumulative impact, and quantum calculations, and had a lead role in assessing damages on more than a dozen major disputes. In addition, Mr. Carter has developed cost and schedule risk analysis models using Monte Carlo simulations to address the uncertainty of estimates and claims.
|
 | Michael J. Vallez, P.E., MBA, LEAN SIX SIGMA is a Principal with Long International and has over 40 years of hands-on and leadership experience in project management, engineering and construction management, cost and schedule control, change management, claims, dispute resolution, and mine and process engineering. He has served in executive management roles in industry, including both the owner and contractor sides, with organizations and contractors working on world-class projects for oil and gas companies, power companies, international mining companies, and other institutions. Mr. Vallez has a proven ability to organize and integrate the work of multi-disciplined technical specialists and project construction teams to achieve corporate financial goals and objectives of return on investment (ROI), safety, operational performance, cost, and time. In all, he has provided leadership on several billion dollars’ worth of projects in the Mining, Power, Oil and Gas, Industrial, Heavy Civil and Commercial sectors. Mr. Vallez has written several books on the subjects of construction management, safety, and effective project leadership.
|
12/28/2019
· ConstructionAn As-Built But-For Schedule Delay Analysis (ABBF) is a retrospective CPM schedule delay analysis technique that determines the earliest date that the required mechanical completion activity, project completion activity, or various milestone activities could have been achieved but-for the owner-caused compensable delays that occurred during the project.
Contractor’s claim submittals and expert reports are often deficient in proving causation, i.e., the cause-effect linkage. These claims generally outline the owner-caused impacts and separately calculate quantum; however, the two are often not linked in any meaningful way. Most claims are settled prior to a decision by a panel, court, or board, and therefore these deficiencies are not made apparent. Yet, a well-prepared claim document which includes a persuasive and accurate causeeffect analysis can greatly improve the contractor’s chances of a successful recovery, either through negotiations or in arbitration/litigation. This analysis is difficult and often costly to prepare, and is therefore not performed in many disputes, which may be the reason why the claims fail.
The leader of a corporation or project is the individual who must ultimately be willing to take responsibility for results. Within the context of an organization or team made up of individuals, it is the collective performance of the individuals, as a team, that defines the results of the whole. While it can be said that the best motivation is internal motivation as opposed to external motivation, the leader is ultimately the one responsible for creating the conditions where motivation can thrive.
11/13/2017
· ConstructionTime is money especially on engineering and construction projects. Because delays in the completion of the project usually result in increased owner, engineer, and contractor costs, the overall time of performance is vital to the financial success of the project. The importance of time is evidenced by the significant role played by CPM schedules, completion dates, and milestones in the bidding and awarding of engineering and construction contracts. The desire to minimize costs and the time of performance often causes the occurrence of acceleration.
In the construction industry, it is largely agreed that overtime work adversely affects labor productivity. However, there is no universally accepted method for estimating the resulting loss of productivity, and many of the studies commonly used to estimate such losses have been subject to criticism by industry experts and the courts.
The Collapsed As-Built Windows Schedule Analysis (AACE® International Recommended Practice 29R-03, Method Implementation Protocol 3.9) is a modeled, subtractive, multiple-base method. It is a retrospective CPM schedule analysis which is typically used to prove entitlement for compensable delay and assess concurrency of delay within a window of time. The analysis simulates the as-built conditions within a schedule window and then delays are removed from the CPM model. If the forecasted project finish date “collapses” but-for or absent compensable delays, then entitlement for compensable time-related costs can be demonstrated. This article addresses the usage of the Collapsed As-Built Windows protocol and the advantages and disadvantages of the methodology.
The "discrete damages/cost variance analysis method" for quantifying construction claim damages involves the specific distribution of all costs incurred on the project rather than quantifying only certain parts of the cost or damage analysis as may be used in the other methods.
ABSTRACT - This paper provides guidelines to commercial construction cost engineers for the development of a plan for obtaining and utilizing subcontractor cost information for use in bidding, procurement, scheduling, change order management, and claim management. The paper is based upon personal field experience gained in cost engineering, scheduling, bidding, planning, contracting, and claim analyses.
A component of a construction claim often relates to the cost, quantity, and quality of the materials that the contractor installed on a project. The contractor frequently purchases these materials and agrees to install the quantities of materials on a unit price basis, i.e., a unit price that includes both the cost of the materials and the cost to install them.
12/17/2012
· ConstructionMost construction contracts, whether they are standard or customized forms, usually contain specific provisions related expressly to the process of giving "notice." The notice generally refers to an obligation on the part of the Contractor to notify the relevant party administering the contract, normally the architect, resident engineer, or owner's representative, of a claim or change event that gives rise to possible additional entitlement for time and/or cost.
The equitable allocation of responsibility for project delays is essential to the resolution of many construction disputes. Contractors frequently assert that they have been delayed for reasons beyond their control. Owners often remain unconvinced that the Contractor is legitimately entitled to a time extension or delay, acceleration and loss of productivity damages.
Geoffrey Beresford Hartwell is a Chartered Engineer who practices as an Arbitrator, Adjudicator and Expert for Determination. Geoffrey is the former Senior Partner of Consulting Mechanical and Electrical Engineers BHA Cromwell House.
Kelly T. Hickel, Co-founder at EWCS, is a Financial and Business Advisor who has served as a senior executive for over 30 years. Mr. Hickel has many years of experience in the technology industry and with turnarounds of troubled companies. Throughout his career, he has arranged numerous private and public company financings and financial restructurings and has raised and/or returned over a $1 billion to investors and lenders. Mr. Hickel served as Turn-around President to Miniscribe Corp., a troubled Fortune 500, $600 million annual revenue disk drive manufacturer, and President of the Maxwell Technology Information Systems Group from 1993 until 1997, during which, Maxwell was the 9th best performing stock on NASDAQ and the #1 performing stock in California in 1996. As Chairman and Chief Restructuring Office of The Tyree Company in Farmingdale, New York, Mr. Hickel was responsible for running the largest oil downstream services company in the northeast. With all of his experience, he then founded and managed emerging Pharmaceutical companies, taking a product through FDA approval for a supplement through distribution in over 2000 retail pharmacy outlets. 
ins, ASA BV/IA, MAFF, CEP, is the Managing Director and heads the valuation, litigation, and advisory services practices at Teknos. He has worked in Silicon Valley for more than 35 years, as a Valuation expert, a Venture Capitalist, and an Investment Banker. Mr. Timmins has overseen 1,000s of valuations, fairness opinions, and solvency opinions in connection with financial reporting, tax compliance, merger and acquisition transactions, financings, spin-offs, and recapitalizations, and litigation. He has also participated in numerous merger and acquisition transactions, private placements, and public offerings during his career. Prior to forming Teknos, Mr. Timmins was a Managing Director at Pagemill Partners, where he created and managed the valuation practice. Before that he was the Managing Director of the Silicon Valley office of NIF Ventures (the venture capital arm of Daiwa Securities SMBC of Japan), and a General Partner of Glenwood Ventures and Glenwood Capital. Earlier in his career, he held positions in investment banking at Hambrecht & Quist and Salomon Brothers. Mr. Timmins has served as an expert witness for more than 60 cases involving valuation, fiduciary duty, and venture capital practice. He has been retained as an expert by both plaintiffs and defendants.
