Florida Office:
Andrew Avalon, PE, PSP
President
8633 Willow Kane Court
Orlando, FL 32835
T: (407) 445-0825 F: (407) 445-0821
Long International provides expert claims analysis, dispute resolution, and project management services to the Process Plant Engineering and Construction industry worldwide. Our primary focus is on petroleum refining, petrochemical, chemical, oil and gas production, mining/mineral processing, power, cogeneration, and other process plant and industrial projects. We also have extensive experience in hospital, commercial and industrial building, pipeline, wastewater, highway and transit, heavy civil, microchip manufacturing, and airport projects.
| Richard J. Long, PE, Founder and Chief Executive Officer of Long International has over 40 years of U.S. and international consulting experience involving construction contract disputes analysis and resolution, arbitration/litigation support and expert testimony, project management, engineering/construction management, cost and schedule control, and process engineering. He has presented and published numerous articles on the subjects of claims analysis, entitlement issues, CPM schedule and damages analyses, cumulative impact claims, and claims prevention. As an internationally recognized expert in the analysis and resolution of complex construction disputes for 30 years, Mr. Long has served as the lead expert on over 300 projects having claims ranging in size from US$100,000 to over US$2 billion.
|
| Andrew Avalon, PE, PSP is President of Long International and has over 30 years of engineering, construction management and claims consulting experience. He is an expert in the preparation and evaluation of construction claims, insurance claims, schedule delay analysis, arbitration/ litigation support, and dispute resolution. Mr. Avalon has prepared more than 30 CPM schedule analyses, expert witness reports, and testified in deposition, mediation, and arbitration proceedings. In addition, he has published numerous articles on the subjects of CPM schedule delay analysis and entitlement issues affecting construction claims and is a contributor to AACE® International’s Recommended Practice No. 29R-03 for Forensic Schedule Analysis. He has served as a Project Manager on numerous claims ranging in size from US$100,000 to over US$1 billion.
|
| W. Tom Thweatt is a Senior Principal with Long International and has over 40 years of engineering, construction, and management consulting experience. He has extensive experience in major U.S. and international refining, chemical, petrochemical, offshore oil & gas development, pipeline, infrastructure, and thermal / hydroelectric power generation projects ranging from US$40 million to US$12 billion. He has worked extensively in projects that were executed by multi-national joint ventures on both the owner’s and the contractor’s sides. Mr. Thweatt has served on Joint Venture and Consortium Executive Committees and has participated directly in claims negotiations and settlement agreements in excess of US$100 million.
|
Contractor’s claim submittals and expert reports are often deficient in proving causation, i.e., the cause-effect linkage. These claims generally outline the owner-caused impacts and separately calculate quantum; however, the two are often not linked in any meaningful way. Most claims are settled prior to a decision by a panel, court, or board, and therefore these deficiencies are not made apparent. Yet, a well-prepared claim document which includes a persuasive and accurate causeeffect analysis can greatly improve the contractor’s chances of a successful recovery, either through negotiations or in arbitration/litigation. This analysis is difficult and often costly to prepare, and is therefore not performed in many disputes, which may be the reason why the claims fail.
The leader of a corporation or project is the individual who must ultimately be willing to take responsibility for results. Within the context of an organization or team made up of individuals, it is the collective performance of the individuals, as a team, that defines the results of the whole. While it can be said that the best motivation is internal motivation as opposed to external motivation, the leader is ultimately the one responsible for creating the conditions where motivation can thrive.
11/13/2017
· ConstructionTime is money especially on engineering and construction projects. Because delays in the completion of the project usually result in increased owner, engineer, and contractor costs, the overall time of performance is vital to the financial success of the project. The importance of time is evidenced by the significant role played by CPM schedules, completion dates, and milestones in the bidding and awarding of engineering and construction contracts. The desire to minimize costs and the time of performance often causes the occurrence of acceleration.
In the construction industry, it is largely agreed that overtime work adversely affects labor productivity. However, there is no universally accepted method for estimating the resulting loss of productivity, and many of the studies commonly used to estimate such losses have been subject to criticism by industry experts and the courts.
The Collapsed As-Built Windows Schedule Analysis (AACE® International Recommended Practice 29R-03, Method Implementation Protocol 3.9) is a modeled, subtractive, multiple-base method. It is a retrospective CPM schedule analysis which is typically used to prove entitlement for compensable delay and assess concurrency of delay within a window of time. The analysis simulates the as-built conditions within a schedule window and then delays are removed from the CPM model. If the forecasted project finish date “collapses” but-for or absent compensable delays, then entitlement for compensable time-related costs can be demonstrated. This article addresses the usage of the Collapsed As-Built Windows protocol and the advantages and disadvantages of the methodology.
The "discrete damages/cost variance analysis method" for quantifying construction claim damages involves the specific distribution of all costs incurred on the project rather than quantifying only certain parts of the cost or damage analysis as may be used in the other methods.
ABSTRACT - This paper provides guidelines to commercial construction cost engineers for the development of a plan for obtaining and utilizing subcontractor cost information for use in bidding, procurement, scheduling, change order management, and claim management. The paper is based upon personal field experience gained in cost engineering, scheduling, bidding, planning, contracting, and claim analyses.
A component of a construction claim often relates to the cost, quantity, and quality of the materials that the contractor installed on a project. The contractor frequently purchases these materials and agrees to install the quantities of materials on a unit price basis, i.e., a unit price that includes both the cost of the materials and the cost to install them.
12/17/2012
· ConstructionMost construction contracts, whether they are standard or customized forms, usually contain specific provisions related expressly to the process of giving "notice." The notice generally refers to an obligation on the part of the Contractor to notify the relevant party administering the contract, normally the architect, resident engineer, or owner's representative, of a claim or change event that gives rise to possible additional entitlement for time and/or cost.
The equitable allocation of responsibility for project delays is essential to the resolution of many construction disputes. Contractors frequently assert that they have been delayed for reasons beyond their control. Owners often remain unconvinced that the Contractor is legitimately entitled to a time extension or delay, acceleration and loss of productivity damages.
James D. Wamble, PE, RLS has over 30 years of experience as a Professional Civil Engineer and Registered Land Surveyor. During the course of his career, Mr. Wamble has worked on land planning, land surveying, or civil engineering projects in all counties of the middle and west Tennessee regions, and several counties in east Tennessee.
Mark E. Rieser, II, MS, PE, AIA, GBC, GEC has over 30 years of experience in the Engineering, Architectural, Construction, and Building Design industry. He provides his clients with a comprehensive knowledge of Engineering, Construction Technology and Construction Standards of Professional Practice.
Prof. Makarand (Mark) Hastak, PhD, PE, CCP, CRIS, is the Professor and the Dernlan Family Head of Construction Engineering and Management as well as Professor of Civil Engineering at Purdue University. Dr. Hastak has been involved with the construction industry for the past 32 years providing his expertise through consulting, research, teaching, and service to the industry. He is a world renowned expert in the area of construction engineering and management including process improvement, disaster risk reduction, resilience and capacity building, infrastructure management, intelligent planning for the built environment, cost control, project management decision-making, risk management, and strategic planning. Dr. Hastak is a Professional Engineer (PE), a Construction Risk Insurance Specialist (CRIS), and a Certified Cost Professional (CCP). Prof. Hastak has worked on numerous projects sponsored by the Construction Industry Institute (CII), NSF, State DOTs, and City Agencies. He has authored over 200 publications on process improvement, project controls, capital rehabilitation planning, strategic planning, and decision-making. He has co-authored a widely used book on Infrastructure Planning, Engineering, and Economics (McGraw-Hill 2006 and 2015). Dr. Hastak served on the Education Board of the Association for Advancement of Cost Engineering (2004-2016). He was Editor for two AACE books, the Skills and Knowledge of Cost Engineering (6th Ed. 2015) and the CCP Certification Study Guide (2nd Ed. 2016). He was also the Editor-in-Chief of the ASCE Journal of Management in Engineering (2009-2016). Dr. Hastak has given over 40 keynotes and invited lectures around the world. As a prominent educator and consultant, he also engages in developing training material and workshops as well as regularly teaching professional courses for the A/E/C industry. His services include consultation, on-site investigation, data collection, assessment, and reporting. He has completed the 
Sanford C. Loy , CCM, B.Arch, MSCE, has 40 years of experience in the Construction Industry. Mr. Loy has Degrees in Architecture and Engineering. A Certified Construction Manager (CCM), he is committed to the Code of Ethics and Standards of Professional Practice established by the Construction Management Association of America. CCM is the ANSI accredited professional designation for construction management and is the gold standard for CM service providers in over 145 countries.
